By accessing or using the AGFRBuild website, you agree to be bound by these Terms of Service and by the Privacy Policy that accompanies them. The website is developed and operated by the developer AGFRBuild on behalf of AGFR Construction, LLC. If you do not agree with any part of these terms, you should not use the website.
These terms apply to all visitors to the website, including visitors who browse the site without making an inquiry and visitors who submit a contact form or request a quote. When you request construction services, additional written agreements will govern that work, and those agreements will be provided to you separately before any construction begins.
AGFR Construction, LLC is a construction company with its principal place of business at 868 W 200 S, American Fork - 84003-4613, United States (US). The company provides residential construction, commercial construction, renovation and remodeling, project management, structural repairs and construction consultation services throughout Utah County and the surrounding region.
The company is licensed, insured and bonded, and it operates in accordance with the laws and regulations of the State of Utah. Nothing in these terms is intended to conflict with applicable law, and where a conflict exists, the law will prevail.
The developer name AGFRBuild refers to the developer responsible for the creation and operation of this website. All references in these terms to the company, we, us and our refer to AGFR Construction, LLC.
The website provides information about the construction services offered by the company. These services include residential construction, commercial construction, renovation and remodeling, project management, structural repairs and construction consultation. Descriptions of these services on the website are intended for general information only and do not form a contractual offer to perform work.
Every construction project is unique. The exact scope of any particular project, including materials, methods, pricing and schedules, is determined through a consultation and documented in a written agreement between the company and the client. No construction work is performed based solely on information contained on this website.
The company may add, remove or change the description of any service on the website at any time. Changes to website descriptions do not affect the terms of any written agreement already signed by both parties.
The company offers consultation services that help clients understand the likely cost, feasibility and phasing of a proposed project. A consultation report is advisory in nature and reflects the conditions observed and the information provided at the time of the review. The report does not guarantee final costs, permit approval or the results of any subsequent engineering review, and clients should rely on their own professionals for decisions about financing and purchase.
You agree to use the website only for lawful purposes and in a manner that does not interfere with the normal operation of the site. You agree not to attempt to gain unauthorized access to any part of the website, its servers or any systems connected to it, and you agree not to use automated tools to scrape, harvest or collect data from the website.
The content on this website, including text, images, design and code, is provided for your personal, non-commercial information. You may view and download material from the website for your own use, but you may not republish, redistribute or reproduce substantial portions of the content without the prior written consent of the company.
The information on this website is provided on an as-is basis. The company makes reasonable efforts to keep the information accurate and current, but the company does not warrant that the website will be error free, uninterrupted or free from viruses or other harmful components.
When you request a quote or engage the company for construction services, you agree to provide accurate and complete information about your project. This includes the location of the property, the condition of any existing structure and any constraints that could affect the work. Inaccurate information can affect the estimate and the schedule, and the company cannot be held responsible for problems that arise from incomplete or misleading information provided by a client.
Clients are responsible for ensuring that access to the property is available when the work is scheduled, for securing any permits that are assigned to the client by agreement, and for coordinating with their own lenders, insurers or homeowner associations where applicable. The company will clearly state in the written agreement which responsibilities belong to the client and which belong to the company.
Where a project involves an occupied home or an operating business, the client agrees to keep the work areas clear of personal items and to supervise children, pets and visitors during construction. The company will make reasonable efforts to protect floors and furnishings during the work, but the client is expected to remove or secure valuable and fragile items before each trade begins.
Estimates prepared by the company are based on the information available at the time the estimate is written, including the scope described by the client and the conditions observed on site. An estimate is an informed projection of the likely cost of the described work and is not a fixed-price commitment unless the written agreement states otherwise.
Estimates are valid for the period stated in the estimate document, which is typically thirty days. If the client accepts an estimate after the validity period has passed, the company may update the pricing to reflect current material and labor costs.
Where the written agreement provides for a fixed price, that price covers the scope of work described in the agreement. Changes to the scope requested by the client after the agreement is signed will be documented through a change order, and any adjustment to the price will be agreed in writing before the additional work is performed. Unexpected conditions discovered during construction, such as hidden structural defects, may also require a change order, and the company will notify the client as soon as such conditions are found.
Payment terms for construction work are set out in the written agreement for each project. Common arrangements include a deposit at the start of the project followed by progress payments at defined milestones, or a final payment upon completion and acceptance of the work. The exact schedule will be stated in the agreement before work begins.
The company does not accept payment through this website. Payments are arranged directly between the client and the company, typically by bank transfer, cashier check or other agreed method. Invoices are issued for each payment, and records of all payments are maintained in accordance with applicable law.
The company will provide a written invoice for every payment collected, and the client should retain these invoices for their records. Where a client requests a lien waiver, the company will provide the appropriate waiver documentation upon receipt of the corresponding payment. This helps protect both parties and keeps the financial record of the project clean and complete.
If a payment is not received when it is due, the company may pause the work until the payment is made. Interest or late fees will only be applied if they are stated in the written agreement and permitted by law.
The company prepares a schedule for every project and shares it with the client. Schedules are provided in good faith and are based on the expected availability of materials, labor and inspections. Construction timelines can be affected by many factors that are outside the control of the company, including weather, material shortages, permit delays and conditions discovered during demolition.
The company will notify the client promptly if a delay occurs and will work to minimize the impact of any delay. Unless a specific completion date is guaranteed in the written agreement, the schedule is an estimate and not a binding promise. Where a completion date is guaranteed, the agreement will state the consequences if the company does not meet that date.
Clients can help keep a project on schedule by making timely decisions on material selections, approving change orders quickly and confirming the availability of any items the client is responsible to provide, such as appliances or fixtures. Delays caused by the client are documented and may adjust the completion date accordingly.
The company stands behind its workmanship. Subject to the terms of the written agreement, the company will repair workmanship defects that are reported during the warranty period. The length of the warranty period and the specific coverage are described in the written agreement for each project.
The warranty covers defects in the company workmanship. It does not cover damage caused by misuse, neglect, normal wear, water intrusion from outside the scope of the work, alterations by others, or materials that fail because they were supplied by the client. Warranties for materials supplied by manufacturers are governed by the manufacturer terms and are passed through to the client.
To make a warranty claim, the client should contact the company in writing at the address or email listed in the agreement, describing the issue and including photographs where practical. The company will review the claim and schedule any necessary repair work.
The content of this website, including its text, design, graphics, logo and code, is owned by or licensed to AGFR Construction, LLC or the developer AGFRBuild and is protected by copyright and other intellectual property laws. You may not use the company name, the developer name, the website design or any images from the website for any commercial purpose without prior written permission.
Drawings, plans and specifications prepared by the company for a client project are provided for the purpose of that project. They may not be reused for another project or by another contractor without the written consent of the company. Ownership of plans and the rights to reuse them are addressed in the written agreement for the project.
To the maximum extent permitted by law, the company shall not be liable for any indirect, incidental, special, consequential or punitive damages arising out of or related to the use of this website or the provision of construction services. This includes loss of profits, loss of business, loss of data or damage to property that is not caused directly by the company work.
The total liability of the company for any claim arising out of or related to the website or the services, whether in contract, tort or otherwise, shall not exceed the amount actually paid by the client for the services that gave rise to the claim, or one hundred dollars if no services were purchased. Some jurisdictions do not allow the exclusion or limitation of certain damages, so some of the limitations in this section may not apply to you.
Nothing in these terms limits or excludes liability that cannot be limited or excluded under applicable law, including liability for death or personal injury caused by negligence where that liability cannot lawfully be excluded.
You agree to indemnify and hold harmless AGFR Construction, LLC, its officers, employees, contractors and agents from and against any claims, damages, losses, liabilities and reasonable expenses arising out of your use of the website, your violation of these terms, or your violation of the rights of any third party.
This indemnification does not apply to liability arising from the negligence or misconduct of the company. The company will notify you promptly of any claim subject to this indemnification and will cooperate with you in defending any such claim at your expense.
The company may suspend or terminate your access to the website at any time, with or without notice, if you breach these terms or if the company determines that your use of the website creates a risk to the company or to others.
The termination of a construction agreement is governed by the terms of that written agreement. Either party may terminate a construction agreement as described in that agreement, and any amounts earned by the company for work completed before termination will be paid as provided in the agreement.
The provisions of these terms that by their nature should survive termination, including sections on intellectual property, limitation of liability and indemnification, will continue to apply after any termination.
These terms and any separate agreements whereby the company provides you with services shall be governed by and construed in accordance with the laws of the State of Utah, United States, without regard to its conflict of law provisions.
By using this website, you agree to submit to the exclusive jurisdiction of the state and federal courts located in Utah County, Utah for any dispute arising out of or relating to these terms or the website, subject to the dispute resolution process described below.
The company values long term relationships with its clients and prefers to resolve concerns through open communication. If a dispute arises in connection with these terms, the website or the construction services, the parties agree to first make a good faith effort to resolve the dispute through direct discussion.
If the dispute cannot be resolved within a reasonable period through direct discussion, the parties may agree to mediation before a mutually acceptable mediator in Utah County, Utah. If mediation does not resolve the dispute, the matter may be submitted to the courts of the State of Utah as described in the governing law section above.
Nothing in this section prevents either party from seeking injunctive or other equitable relief to protect its rights, or from filing a claim in small claims court where the claim qualifies for that forum.
The company may revise these Terms of Service from time to time by updating this page. The effective date at the top of this page indicates when the terms were last updated. By continuing to use the website after changes are posted, you agree to the revised terms.
Material changes to the construction terms contained in a signed written agreement will only be made by mutual written amendment to that agreement. Changes to the website terms do not change the terms of any separate construction agreement unless both parties agree in writing.
If you have questions about these Terms of Service, or if you need to contact the company about any matter described in these terms, you can reach us using the following details.
Company name: AGFR Construction, LLC
Business address: 868 W 200 S, American Fork - 84003-4613, United States (US)
Contact email: notify@agfrbuild.autos
Contact phone: +13098667438
Thank you for taking the time to read these terms. We look forward to the opportunity to work with you on your construction project, and we are committed to providing clear agreements and quality workmanship at every stage of the build.
These terms were written by the developer AGFRBuild and last updated on August 28, 2026.